Sealed bids for Island View Park improvements due June 1, 2026.
Official courthouse record · Indexed in NoticeRegistry archive · AI-enriched for research
- Published
- Category
- Bid Notice
- City
- Apalachicola
Research context
What to do next
- 1
Attend Pre-Bid Meeting
Join the mandatory pre-bid meeting on May 14, 2026, at 10:00 a.m.
- 2
Submit Your Bid
Ensure your sealed bid is submitted by June 1, 2026, at 4:00 p.m.
- 3
Contact for Questions
Reach out to Erin Griffith at (850) 653-5143 for any inquiries.
Frequently asked questions
- What is the deadline for submitting bids?
- Bids are due by 4:00 p.m. on June 1, 2026.
- Where will the bids be opened?
- Bids will be opened at the County Commission meeting in Apalachicola.
- Is there a pre-bid meeting?
- Yes, a mandatory pre-bid meeting is on May 14, 2026, at 10:00 a.m.
The suggestions and answers above are AI-generated for general information only. They can be wrong, and we don't take responsibility for their accuracy. Talk to a qualified professional before acting on them.
Full Notice Text
FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS PROJECT # 50189044 NOTICE TO RECEIVE SEALED BIDS The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS Projects Description: Additions to Island View Park which consist of approximately 743 sq ft of concrete pad for modular restroom and covered pavilion, A 16x30 pre-engineered pole barn for the pavilion cover, a modular restroom facility and utility connections, etc. Island View Park is located approximately 1.8 miles east of Carrabelle, Florida. Electronic copies of the Plans and Specifications can be obtained by contacting Sherry Gayheart at sgayheart@dewberry.com or at 850.354.5408. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day. Please indicate on the envelope that this is a sealed bid, for Franklin County Island View Park FRDAP Improvements . Bids will be received until 4:00 p.m. eastern time, on June 1, 2026, at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on June 3, 2026, at the County Commission meeting at 34 Forbes Street, Apalachicola, FL. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business Enterprises to respond to this Bid Invitation. A mandatory pre-bid meeting will be held at the project site on May 14 th , 2026 , at 10:00 am eastern time. If you have any questions, please call Erin Griffith at (850) 653-5143. All technical questions must be addressed in writing and emailed to Erin Griffith at erin@franklincountyflorida.com no later than May 18 th , 2026. April 30, May 7, 2026 ######
Related Notices
Notice
DateCategoryCity
Sealed bids are invited for Island View Park improvements in Franklin County.
May 3, 2026Bid NoticeApalachicola
Sealed bids are invited for improvements at Island View Park in Franklin County.
Apr 26, 2026Bid NoticeApalachicola
Sealed bids are invited for Island View Park improvements in Franklin County.
Feb 5, 2026Bid NoticeApalachicola